66.29(7) (7)Bidder's certificate. On all contracts the bidder shall incorporate and make a part of the bidder's proposal for the doing of any work or labor or the furnishing of any material in or about any public work or contract of the municipality a sworn statement by the bidder, or if not an individual by one authorized, that the bidder or authorized person so swearing has examined and carefully prepared the proposal from the plans and specifications and has checked the same in detail before submitting the proposal or bid to the municipality, board, department or officer charged with the letting of bids and also at the same time as a part of the proposal, submit a list of the subcontractors the bidder proposes to contract with, and the class of work to be performed by each, provided that to qualify for inclusion in the bidder's list a subcontractor must first submit a bid in writing, to the general contractor at least 48 hours prior to the time of the bid closing, which list shall not be added to nor altered without the written consent of the municipality. A proposal of a bidder shall not be invalid if any subcontractor and the class of work to be performed by the subcontractor has been omitted from a proposal; such omission shall be considered as inadvertent, or that the bidder will perform the work personally.
66.29(8) (8)Settlement of disputes; defaults. Whenever there is a dispute between the contractor or surety or the municipality as to the determination whether there is a compliance with the provisions of the contract as to the hours of labor, wages, residence, character, and classification of workmen employed by any contractor, the determination of the municipality shall be final, and in case of violation of said provisions, the municipality may declare the contract in default and request the surety to perform or relet upon advertisement the remaining portion of the contract.
66.29(9) (9)Estimates and release of funds.
66.29(9)(a)(a) Definition. In this subsection, "municipality" means the state, except the department of transportation, and any town, city, village, county, school district, technical college district, board of school directors, sewer district, drainage district, or any other public or quasi-public corporation, officer, board, or other public body.
66.29(9)(b) (b) Retained percentages. As the work progresses under any contract involving $1,000 or more for the construction, execution, repair, remodeling or improvement of any public work or building or for the furnishing of any supplies or materials, whether or not proposals for which are required to be advertised by law, the municipality, from time to time, shall grant to the contractor an estimate of the amount and proportionate value of the work done, which shall entitle the contractor to receive the amount thereof, less the retainage, from the proper fund. On all such contracts, the retainage shall be an amount equal to 10% of said estimate until 50% of the work has been completed. At 50% completion, further partial payments shall be made in full to the contractor and no additional amounts may be retained unless the architect or engineer certifies that the job is not proceeding satisfactorily, but amounts previously retained shall not be paid to the contractor. At 50% completion or any time thereafter when the progress of the work is not satisfactory, additional amounts may be retained but in no event shall the total retainage be more than 10% of the value of the work completed. Upon substantial completion of the work, an amount retained may be paid to the contractor. When the work has been substantially completed except for work which cannot be completed because of weather conditions, lack of materials or other reasons which in the judgment of the municipality are valid reasons for noncompletion, the municipality may make additional payments, retaining at all times an amount sufficient to cover the estimated cost of the work still to be completed or in the alternative may pay out the entire amount retained and receive from the contractor guarantees in the form of a bond or other collateral sufficient to ensure completion of the job. For the purposes of this section, estimates may include any fabricated or manufactured materials and components specified, previously paid for by contractor and delivered to the work or properly stored and suitable for incorporation in the work embraced in the contract.
66.29 Annotation Under (5), a bidder has no "right" to withdraw its bid or demand that it be amended. Under the terms of the proposal, the commission was entitled to retain the deposit upon plaintiff's failure to execute the contract within 10 days of the notice of award. Nelson Inc. v. Sewerage Comm. of Milw. 72 W (2d) 400, 241 NW (2d) 390.
66.29 Annotation Acceptance of the bid is a precondition to forfeiture of the bidder's deposit under (5). Gaastra v. Village of Fairwater, 77 W (2d) 7, 252 NW (2d) 60.
66.29 Annotation Where bid error was discovered after contract was let, dispute was governed by arbitration clause in contract, not by (5). Turtle Lake v. Orvedahl Const., 135 W (2d) 385, 400 NW (2d) 475 (Ct. App. 1986).
66.29 Annotation Where a governmental entity determines that an apparent low bidder is entitled to relief from an erroneous bid under (5), the bidder should be allowed to correct his bid. 62 Atty. Gen. 144.
66.29 Annotation Police cars need not be purchased by competitive bid since they are "equipment" and not "supplies [or] material." 66 Atty. Gen. 284.
66.29 AnnotationMunicipalities may require bidders to include list of subcontractors under (7). 76 Atty. Gen. 29.
66.293 66.293 Contractor's failure to comply with municipal wage scale.
66.293(1)(1)Definitions. In this section:
66.293(1)(a) (a) "Area" means the county in which a proposed project that is subject to this section is located or, if the department determines that there is insufficient wage data in that county, "area" means those counties that are contiguous to that county or, if the department determines that there is insufficient wage data in those counties, "area" means those counties that are contiguous to those counties or, if the department determines that there is insufficient wage data in those counties, "area" means the entire state or, if the department is requested to review a determination under sub. (3) (br), "area" means the city, village or town in which a proposed project that is subject to this section is located.
66.293(1)(b) (b) "Department" means the department of industry, labor and job development.
66.293 Note NOTE: 1995 Wis. Act 289, s. 275, authorizes the department of industry, labor and job development to use the name "department of workforce development" for any official purpose.
66.293(1)(c) (c) "Hourly basic rate of pay" has the meaning given in s. 103.49 (1) (b).
66.293(1)(cm) (cm) "Insufficient wage data" has the meaning given in s. 103.49 (1) (bg).
66.293(1)(d) (d) "Local governmental unit" means a political subdivision of this state, a special purpose district in this state, an instrumentality or corporation of such a political subdivision or special purpose district, a combination or subunit of any of the foregoing or an instrumentality of the state and any of the foregoing.
66.293(1)(e) (e) "Multiple-trade public works project" has the meaning given in s. 103.49 (1) (bm).
66.293(1)(f) (f) "Prevailing hours of labor" has the meaning given in s. 103.49 (1) (c).
66.293(1)(g) (g) "Prevailing wage rate" for any trade or occupation engaged in the erection, construction, remodeling, repairing or demolition of any project of public works in any area means the hourly basic rate of pay, plus the hourly contribution for health insurance benefits, vacation benefits, pension benefits and any other bona fide economic benefit, paid directly or indirectly, for a majority of the hours worked in the trade or occupation on projects in the area, or if there is no rate at which a majority of the hours worked in the trade or occupation on projects in the area is paid, then the prevailing wage rate for any trade or occupation engaged in the erection, construction, remodeling, repairing or demolition of any project of public works in any area shall be the average hourly basic rate of pay, weighted by the number of hours worked, plus the average hourly contribution, weighted by the number of hours worked, for health insurance benefits, vacation benefits, pension benefits and any other bona fide economic benefit, paid directly or indirectly for all hours worked at the hourly basic rate of pay of the highest-paid 51% of hours worked in that trade or occupation on projects in that area.
66.293(1)(h) (h) "Secretary" means the secretary of industry, labor and job development.
66.293(1)(i) (i) "Single-trade public works project" has the meaning given in s. 103.49 (1) (e).
66.293(1)(j) (j) "Truck driver" has the meaning given in s. 103.49 (1) (g).
66.293(3) (3)Prevailing wage rates and hours of labor.
66.293(3)(am)(am) Every local governmental unit, before making a contract by direct negotiation or soliciting bids on a contract, for the erection, construction, remodeling, repairing or demolition of any project of public works, including a highway, street or bridge construction project, shall apply to the department to determine the prevailing wage rate and prevailing hours of labor for each trade or occupation required in the work contemplated. The department shall make such investigations and hold such public hearings as may be necessary to define the trades or occupations that are commonly employed on projects that are subject to this section and to inform itself as to the prevailing wage rates and prevailing hours of labor in all areas of the state for those trades or occupations with a view to ascertaining the prevailing wage rate and prevailing hours of labor for each such trade or occupation. The department shall issue its determination within 30 days after receiving the request and shall file the same with the local governmental unit applying therefor.
66.293(3)(ar) (ar) The department shall, by January 1 of each year, compile the prevailing wage rates and the prevailing hours of labor for each trade or occupation in each area. The compilation shall, in addition to the current prevailing wage rates and prevailing hours of labor, include future prevailing wage rates and prevailing hours of labor when those prevailing wage rates and prevailing hours of labor can be determined for any trade or occupation in any area and shall specify the effective date of those future prevailing wage rates and prevailing hours of labor. If a construction project extends into more than one area there shall be but one standard of prevailing wage rates and prevailing hours of labor for the entire project.
66.293(3)(av) (av) In determining prevailing wage rates under par. (am) or (ar), the department may not use data from projects that are subject to this section, s. 103.49 or 103.50 or 40 USC 276a unless the department determines that there is insufficient wage data in the area to determine those prevailing wage rates, in which case the department may use data from projects that are subject to this section, s. 103.49 or 103.50 or 40 USC 276a.
66.293(3)(bm) (bm) Any person may request a recalculation of any portion of a determination within 30 days after the initial determination date if the person submits evidence with the request showing that the prevailing wage rate or prevailing hours of labor for any given trade or occupation included in the initial determination does not represent the prevailing wage rate or prevailing hours of labor for that trade or occupation in the area. Such evidence shall include wage rate and hours of labor information for work performed in the contested trade or occupation area within the previous 12 months. The department shall affirm or modify the initial determination within 15 days after the date on which the department receives the request for recalculation.
66.293(3)(br) (br) In addition to the recalculation under par. (bm), the local governmental unit that requested the determination under this subsection may request a review of any portion of a determination within 30 days after the date of issuance of the determination if the local governmental unit submits evidence with the request showing that the prevailing wage rate or prevailing hours of labor for any given trade or occupation included in the determination does not represent the prevailing wage rate or prevailing hours of labor for that trade or occupation in the city, village or town in which the proposed project is located. That evidence shall include wage rate and hours of labor information for the contested trade or occupation on at least 3 similar projects located in the city, village or town where the proposed project is located and on which some work has been performed within the previous 12 months and which were considered by the department in issuing its most recent compilation under par. (ar). The department shall affirm or modify the determination within 15 days after the date on which the department receives the request for review.
66.293(3)(dm) (dm) A reference to the prevailing wage rates and prevailing hours of labor determined by the department or a local governmental unit exempted under sub. (6) shall be published in the notice issued for the purpose of securing bids for the project. If any contract or subcontract for a project of public works, including a highway, street or bridge construction project, is entered into, the prevailing wage rates and prevailing hours of labor determined by the department or exempted local governmental unit shall be physically incorporated into and made a part of the contract or subcontract, except that for a minor subcontract, as determined by the department, the department shall prescribe by rule the method of notifying the minor subcontractor of the prevailing wage rates and prevailing hours of labor applicable to the minor subcontract. The prevailing wage rates and prevailing hours of labor applicable to a contract or subcontract may not be changed during the time that the contract or subcontract is in force. No person described in sub. (4) may be paid less than the prevailing wage rate in the same or most similar trade or occupation determined under this subsection; nor may he or she be permitted to work a greater number of hours per day or per calendar week than the prevailing hours of labor determined under this subsection, unless he or she is paid for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times his or her hourly basic rate of pay.
66.293(4) (4)Covered employes.
66.293(4)(a)(a) All of the following employes shall be paid the prevailing wage rate determined under sub. (3) and may not be permitted to work a greater number of hours per day or per calendar week than the prevailing hours of labor determined under sub. (3), unless they are paid for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times their hourly basic rate of pay:
66.293(4)(a)1. 1. All laborers, workers, mechanics and truck drivers employed on the site of a project that is subject to this section, or employed to deliver mineral aggregate such as sand, gravel or stone that is immediately incorporated into the work, and not stockpiled or further transported by truck, to or from the site of a project that is subject to this section by depositing the material substantially in place, directly or through spreaders from the transporting vehicle, or employed to transport excavated material or spoil from and return to the site of a project that is subject to this section.
66.293(4)(a)2. 2. All laborers, workers, mechanics and truck drivers employed in the manufacturing or furnishing of materials, articles, supplies or equipment on the site of a project that is subject to this section or from a facility dedicated exclusively, or nearly so, to a project that is subject to this section by a contractor, subcontractor, agent or other person performing any work on the site of the project.
66.293(4)(b) (b) Notwithstanding par. (a), a laborer, worker, mechanic or truck driver who is regularly employed in the processing, manufacturing or delivery of materials or products by or for a commercial establishment that has a fixed place of business from which the establishment regularly supplies processed or manufactured materials or products is not entitled to receive the prevailing wage rate determined under sub. (3) or to receive at least 1.5 times his or her hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor determined under sub. (3).
66.293(4)(c) (c) A truck driver who is an owner-operator of a truck shall be paid separately for his or her work and for the use of his or her truck.
66.293(5) (5)Nonapplicability. This section does not apply to any single-trade public works project, including a highway, street or bridge construction project, for which the estimated project cost of completion is below $30,000 or an amount determined by the department under this subsection or to any multiple-trade public works project, including a highway, street or bridge construction project, for which the estimated project cost of completion is below $150,000 or an amount determined by the department under this subsection. The department shall adjust those dollar amounts every year, the first adjustment to be made not sooner than December 1, 1997. The adjustments shall be in proportion to any change in construction costs since the effective date of the dollar amounts established under this subsection.
66.293(6) (6)Exemptions. The department, upon petition of any local governmental unit, shall issue an order exempting the local governmental unit from applying to the department for a determination under sub. (3) when it is shown that an ordinance or other enactment of the local governmental unit sets forth standards, policy, procedure and practice resulting in standards as high or higher than those under this section.
66.293(8) (8)Posting. For the information of the employes working on the project, the prevailing wage rates and prevailing hours of labor determined by the department or exempted local governmental unit and the provisions of subs. (10) (a) and (11) (a) shall be kept posted by the local governmental unit in at least one conspicuous and easily accessible place on the site of the project or, if there is no common site on the project, at the place normally used by the local governmental unit to post public notices.
66.293(9) (9)Compliance.
66.293(9)(a)(a) When the department finds that a local governmental unit has not requested a determination under sub. (3) (am) or that a local governmental unit, contractor or subcontractor has not physically incorporated a determination into a contract or subcontract as required under this section or has not notified a minor subcontractor of a determination in the manner prescribed by the department by rule promulgated under sub. (3) (dm), the department shall notify the local governmental unit, contractor or subcontractor of such noncompliance and shall file the determination with the local governmental unit, contractor or subcontractor within 30 days after such notice.
66.293(9)(b) (b) Upon completion of a project and before receiving final payment for his or her work on the project, each agent or subcontractor shall furnish the contractor with an affidavit stating that the agent or subcontractor has complied fully with the requirements of this section. A contractor may not authorize final payment until such an affidavit is filed in proper form and order.
66.293(9)(c) (c) Upon completion of a project and before receiving final payment for his or her work on the project, each contractor shall file with the local governmental unit authorizing the work an affidavit stating that the contractor has complied fully with the requirements of this section and that the contractor has received an affidavit under par. (b) from each of the contractor's agents and subcontractors. A local governmental unit may not authorize a final payment until such an affidavit is filed in proper form and order. If a local governmental unit authorizes a final payment before such an affidavit is filed in proper form and order or if the department determines, based on the greater weight of the credible evidence, that any person specified in sub. (4) has been or may have been paid less than the prevailing wage rate or less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor and requests that the local governmental unit withhold all or part of the final payment, but the local governmental unit fails to do so, the local governmental unit is liable for all back wages payable up to the amount of that final payment.
66.293(10) (10)Records; inspection; enforcement.
66.293(10)(a)(a) Each contractor, subcontractor or agent thereof performing work on a project that is subject to this section shall keep full and accurate records clearly indicating the name and trade or occupation of every person described in sub. (4) and an accurate record of the number of hours worked by each of those persons and the actual wages paid therefor.
66.293(10)(b) (b) The department or the contracting local governmental unit may demand and examine, and it shall be the duty of every contractor, subcontractor and agent thereof to keep and furnish to the department or local governmental unit, copies of payrolls and other records and information relating to the wages paid to persons described in sub. (4) for work to which this section applies. The department may inspect records in the manner provided in chs. 103 to 106.Every contractor, subcontractor or agent performing work on a project that is subject to this section is subject to the requirements of chs. 103 to 106 relating to the examination of records.
66.293(10)(c) (c) If requested by any person, the department shall inspect the payroll records of any contractor, subcontractor or agent performing work on a project that is subject to this section to ensure compliance with this section. If the contractor, subcontractor or agent subject to the inspection is found to be in compliance and if the person making the request is a person specified in sub. (4), the department shall charge the person making the request the actual cost of the inspection. If the contractor, subcontractor or agent subject to the inspection is found to be in compliance and if the person making the request is not a person specified in sub. (4), the department shall charge the person making the request $250 or the actual cost of the inspection, whichever is greater.
66.293(10)(d) (d) Section 103.005 (5) (f), (11), (12) and (13) applies to this section, except that s. 103.005 (12) (a) does not apply to any person who fails to provide any information to the department to assist the department in determining prevailing wage rates or prevailing hours of labor under sub. (3) (am) or (ar). Section 111.322 (2m) applies to discharge or other discriminatory acts arising in connection with any proceeding under this section, including proceedings under sub. (11) (a).
66.293(11) (11)Liability and penalties.
66.293(11)(a)(a) Any contractor, subcontractor or agent thereof, who fails to pay the prevailing wage rate determined by the department under sub. (3) or who pays less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor determined under sub. (3), shall be liable to any affected employe in the amount of his or her unpaid wages or his or her unpaid overtime compensation and in an additional equal amount as liquidated damages. An action to recover the liability may be maintained in any court of competent jurisdiction by any employe for and in behalf of that employe and other employes similarly situated. No employe may be a party plaintiff to any such action unless the employe consents in writing to become such a party and the consent is filed in the court in which the action is brought. Notwithstanding s. 814.04 (1), the court shall, in addition to any judgment awarded to the plaintiff, allow reasonable attorney fees and costs to be paid by the defendant.
66.293(11)(b)1.1. Except as provided in subds. 2., 4. and 6., any contractor, subcontractor or agent thereof who violates this section may be fined not more than $200 or imprisoned for not more than 6 months or both. Each day that any such violation continues shall be considered a separate offense.
66.293(11)(b)2. 2. Whoever induces any individual who seeks to be or is employed on any project that is subject to this section to give up, waive or return any part of the wages to which the individual is entitled under the contract governing such project, or who reduces the hourly basic rate of pay normally paid to an employe for work on a project that is not subject to this section during a week in which the employe works both on a project that is subject to this section and on a project that is not subject to this section, by threat not to employ, by threat of dismissal from such employment or by any other means is guilty of an offense under s. 946.15 (1).
66.293(11)(b)3. 3. Any person employed on a project that is subject to this section who knowingly permits a contractor, subcontractor or agent thereof to pay him or her less than the prevailing wage rate set forth in the contract governing such project, who gives up, waives or returns any part of the compensation to which he or she is entitled under the contract, or who gives up, waives or returns any part of the compensation to which he or she is normally entitled for work on a project that is not subject to this section during a week in which the person works both on a project that is subject to this section and on a project that is not subject to this section, is guilty of an offense under s. 946.15 (2).
66.293(11)(b)4. 4. Whoever induces any individual who seeks to be or is employed on any project that is subject to this section to permit any part of the wages to which the individual is entitled under the contract governing such project to be deducted from the individual's pay is guilty of an offense under s. 946.15 (3), unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from an individual who is working on a project that is subject to 40 USC 276c.
66.293(11)(b)5. 5. Any person employed on a project that is subject to this section who knowingly permits any part of the wages to which he or she is entitled under the contract governing such project to be deducted from his or her pay is guilty of an offense under s. 946.15 (4), unless the deduction would be permitted under 29 CFR 3.5 or 3.6 from a person who is working on a project that is subject to 40 USC 276c.
66.293(11)(b)6. 6. Subdivision 1. does not apply to any person who fails to provide any information to the department to assist the department in determining prevailing wage rates or prevailing hours of labor under sub. (3) (am) or (ar).
66.293(12) (12)Debarment.
66.293(12)(a)(a) Except as provided under pars. (b) and (c), the department shall notify any local governmental unit applying for a determination under sub. (3) and any local governmental unit exempted under sub. (6) of the names of all persons whom the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor determined under sub. (3) at any time in the preceding 3 years. The department shall include with any such name the address of such person and shall specify when such person failed to pay the prevailing wage rate and when such person failed to pay less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor. A local governmental unit may not award any contract to such person unless otherwise recommended by the department or unless at least 3 years have elapsed from the date the department issued its findings or the date of final determination by a court of competent jurisdiction, whichever is later.
66.293(12)(b) (b) The department may not include in a notification under par. (a) the name of any person on the basis of having let work to a person whom the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor determined under sub. (3).
66.293(12)(c) (c) This subsection does not apply to any contractor, subcontractor or agent who in good faith commits a minor violation of this section, as determined on a case-by-case basis through administrative hearings with all rights to due process afforded to all parties or who has not exhausted or waived all appeals.
66.293(12)(d) (d) Any person submitting a bid on a project that is subject to this section shall be required, on the date the person submits the bid, to identify any construction business in which the person, or a shareholder, officer or partner of the person, if the person is a business, owns, or has owned at least a 25% interest on the date the person submits the bid or at any other time within 3 years preceding the date the person submits the bid, if the business has been found to have failed to pay the prevailing wage rate determined under sub. (3) or to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor determined under sub. (3).
66.293(12)(e) (e) The department shall promulgate rules to administer this subsection.
66.293 Annotation Liability of prime contractor for damages to employes of a subcontractor under s. 779.14 (2) did not include wage penalties under s. 66.293 (3); consent to be a named party under s. (3) may occur after one year where the action is for damages under s 66.293 in the name of the plaintiffs and other similarly situated employes and was filed within the one year time period. Strong v. C.I.R., Inc. 184 W (2d) 619,     NW (2d) (1994).
66.293 Annotation This section is inapplicable to private corporation contracting for medical center. 61 Atty. Gen. 426.
66.293 Annotation See note to 66.521, citing 63 Atty. Gen. 145.
66.293 Annotation Municipalities are subject to (3) on contracts for any project of public works, even if done by the turnkey method. 64 Atty. Gen. 100.
66.295 66.295 Authority to pay for public work done in good faith.
66.295(1)(1) If any city, village, town or county has received and enjoyed or is enjoying any benefits or improvements furnished prior to March 1, 1973, under any contract which was no legal obligation on such city, village, town or county and which contract was entered into in good faith and has been fully performed and the work has been accepted by the proper officials, so as to impose a moral obligation upon such city, village, town or county to pay therefor, such city, village, town or county, by resolution of its governing body and in consideration of such moral obligation, may pay to the person furnishing such benefits or improvements the fair and reasonable value of such benefits and improvements.
66.295(2) (2) The fair and reasonable value of such benefits and improvements and the funds out of which payment therefor shall be made shall be determined by the governing body of the city, village, town or county. Such payments may be made out of any available funds, and the governing body has authority, if necessary, to levy and collect taxes in sufficient amount to meet such payments.
66.295(3) (3) Where payment for any benefits or improvements under subs. (1) and (2) is authorized by the governing body of the city, village or town and where special assessments shall have been levied for any portion of the benefits or improvements prior to the authorization of such payment, the local authorities shall proceed to make a new assessment of benefits and damages in the manner provided for the original assessment, except that steps required in the laws relating to the original assessment to be taken prior to the ordering or doing of such benefits or improvements may be taken after the authorization of such payment with the same effect as if taken prior to the ordering or doing of such benefits or improvements. The owner of any property affected by a reassessment may appeal in the same manner as from an original assessment. On a reassessment, full credit shall be given for all money collected under an original assessment for the benefits and improvements.
66.295 History History: 1973 c. 97; 1993 a. 246.
66.295 Annotation See note following 62.15 citing Blum v. Hillsboro, 49 W (2d) 667, 183 NW (2d) 47.
66.296 66.296 Discontinuance of streets and alleys.
66.296(1) (1) The whole or any part of any road, street, slip, pier, lane or paved alley, in any 2nd, 3rd or 4th class city or in any village or town, may be discontinued by the common council or village or town board upon the written petition of the owners of all the frontage of the lots and lands abutting upon the portion thereof sought to be discontinued, and of the owners of more than one-third of the frontage of the lots and lands abutting on that portion of the remainder thereof which lies within 2,650 feet of the ends of the portion to be discontinued, or lies within so much of that 2,650 feet as shall be within the corporate limits of the city, village or town. The beginning and ending of an alley shall be considered to be within the block in which it is located. This subsection does not apply to a highway upon the line between 2 towns that is subject to s. 80.11.
66.296(1m) (1m) The whole or any part of any unpaved alley in any 2nd, 3rd or 4th class city or in any village or town may be discontinued by the common council or village or town board upon the written petition of the owners of more than 50% of the frontage of the lots and lands abutting upon the portion thereof sought to be discontinued. The beginning and ending of an alley shall be considered to be within the block in which it is located. This subsection does not apply to a highway upon the line between 2 towns that is subject to s. 80.11.
66.296(2) (2)
66.296(2)(a)(a) As an alternative, proceedings covered by this section may be initiated by the common council or village or town board by the introduction of a resolution declaring that since the public interest requires it, the whole or any part of any road, street, slip, pier, lane or alley in the city, village or town is thereby vacated and discontinued.
66.296(2)(b) (b) A hearing on the passage of such resolution shall be set by the common council or village or town board on a date which shall not be less than 40 days thereafter. Notice of the hearing shall be given as provided in sub. (5), except that in addition notice of such hearing shall be served on the owners of all of the frontage of the lots and lands abutting upon the portion thereof sought to be discontinued in a manner provided for the service of summons in circuit court at least 30 days before such hearing. When such service cannot be made within the city, village or town, a copy of the notice shall be mailed to the owner's last-known address at least 30 days before the hearing.
66.296(2)(c) (c) No discontinuance of the whole or any part of any road, street, slip, pier, lane or paved alley shall be ordered if a written objection to the proposed discontinuance is filed with the city, village or town clerk by any of the owners abutting on the portion sought to be discontinued or by the owners of more than one-third of the frontage of the lots and lands abutting on that portion of the remainder thereof which lies within 2,650 feet from the ends of the portion proposed to be discontinued; or which lies within so much of said 2,650 feet as shall be within the corporate limits of the city, village or town. The beginning and ending of an alley shall be considered to be within the block in which it is located.
66.296(2)(d) (d) No discontinuance of an unpaved alley shall be ordered if a written objection to a proposed discontinuance is filed with the city, village or town clerk by the owner of one parcel of land that abuts the portion of the alley to be discontinued and if the alley provides the only access to off-street parking for the parcel of land owned by the objector.
66.296(2m) (2m) For the purpose of this section, the narrowing, widening, extending or other alteration of any road, street, lane or alley does not constitute a discontinuance of any part of the former road, street, lane or alley, including any right-of-way, which is included within the right-of-way for the new road, street, lane or alley.
66.296(3) (3) Whenever any of the lots or lands subject to this section is owned by the state, county, city, village or town, or by a minor or incompetent person, or the title thereof is held in trust, as to all lots and lands so owned or held, petitions for discontinuance or objections to discontinuance may be signed by the governor, chairperson of the board of supervisors of the county, mayor of the city, president of the village, chairperson of the town board, guardian of the minor or incompetent person, or the trustee, respectively, and the signature of any private corporation may be made by its president, secretary or other principal officer or managing agent.
66.296(4) (4) The city council or village or town board may by resolution discontinue any alley or any portion thereof which has been abandoned, at any time after the expiration of 5 years from the date of the recording of the plat by which it was dedicated. Failure or neglect to work or use any alley or any portion thereof for a period of 5 years next preceding the date of notice provided for in sub. (5) shall be considered an abandonment for the purpose of this section.
66.296(5) (5) Notice stating when and where the petition or resolution will be acted upon and stating what road, street, slip, pier, lane or alley, or part thereof, is proposed to be discontinued, shall be published as a class 3 notice, under ch. 985.
Loading...
Loading...
This is an archival version of the Wis. Stats. database for 1995. See Are the Statutes on this Website Official?